An official website of the United States Government
570.703 GSAR contract clauses.
(a) Insert clauses substantially the same as the following in solicitations and contracts for leasehold interests in real property that exceed the simplified lease acquisition threshold, unless the contracting officer determines that a clause is not appropriate. The contracting officer shall document the file with the basis for omitting or substantially changing a clause. A deviation is not required under section 570.704 to determine that a clause in this section is not appropriate. The following clauses may be inserted in solicitations and contracts for leasehold interests in real property at or below the simplified lease acquisition threshold.
| Examination of Records by GSA. | |
| Definitions. Insert this clause if including the clause at 552.270-28. | |
| Subletting and Assignment. | |
| Maintenance of Building and Premises—Right of Entry. | |
| Fire and Casualty Damage. | |
| Compliance with Applicable Law. | |
| Inspection—Right of Entry. | |
| Failure in Performance. | |
| Successors Bound. | |
| Alterations. | |
| Proposals for Adjustment. | |
| Changes. | |
| Liquidated Damages. Insert this clause in solicitations and contracts if you have a critical requirement to meet the delivery date and you cannot establish an actual cost for the loss to the Government resulting from late delivery. | |
| Adjustment for Vacant Premises. | |
| Delivery and Condition. | |
| Default in Delivery—Time Extensions. | |
| Progressive Occupancy. | |
| Payment. | |
| Effect of Acceptance and Occupancy. | |
| Default by Lessor During the Term. | |
| Subordination, Nondisturbance and Attornment. | |
| Statement of Lease. | |
| Substitution of Tenant Agency. | |
| No Waiver. | |
| Integrated Agreement. | |
| Mutuality of Obligation. | |
| Acceptance of Space. |
(b) Insert the following clauses in solicitations and contracts for leasehold interests in real property:
| Price Adjustment for Illegal Improper Activity. | |
| Prompt Payment. | |
| Covenant Against Contingent Fees. |
(c)Insert the representation clause at 552.270-33, Foreign Ownership and Financing Representation for High-Security Leased Space, in novations, solicitations and contracts for leased space that:
(1)Will be occupied by Federal employees for nonmilitary activities; and
(2)Has a facility security level of III, IV, or V.
(d)Insert the clause at 552.270-34 Access Limitations for High-Security Leased Space, in novations, solicitations and contracts for leased space that:
(1)Will be occupied by Federal employees for nonmilitary activities; and
(2)Has a facility security level of III, IV, or V.
