An official website of the United States Government
Subpart 832.1 - Non-Commercial Item Purchase Financing
832.111 Contract clauses for noncommercial purchases.
832.111-70 VA contract clauses for non-commercial purchases.
(a)
(1) Insert the clause at 852.232-70, Payments Under Fixed-Price Construction Contracts (Without NAS-CPM) in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract does not require use of the “Network Analysis System - Critical Path Method (NAS-CPM).”
(2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.
(b)
(1) Insert the clause at 852.232-71, Payments Under Fixed-Price Construction Contracts (Including NAS-CPM), in solicitations and contracts that contain the FAR clause at 52.232-5, Payments Under Fixed-Price Construction Contracts, and if the solicitation or contract requires use of the “Network Analysis System - Critical Path Method (NAS-CPM).”
(2) If the solicitation or contract includes guarantee period services, the contracting officer shall use the clause with its Alternate I.
