FAR Overhaul - Part 36
Part 36 - Construction and Architect-Engineer Contracts
Subpart 36.1 - Pre-solicitation
36.101-1 Acquisition Strategy.
36.101-2 Use of two-phase design-build selection procedures..
36.101-4 Advance notices and solicitations.
36.101-6 Government cost estimate.
36.102 Architect-Engineer Services.
36.102-2 Contracting procedures and competition.
36.102-3 Government cost estimate.
Subpart 36.2 - Evaluation and award
36.201-2 Standard and optional forms.
36.202 Architect and engineering services.
36.202-4 Short selection process for contracts not to exceed the simplified acquisition threshold.
36.000 Scope of part.
This part prescribes policies and procedures for construction, which includes dismantling, demolition or removal of improvements; and architect-engineer services.
36.001 Definition.
As used in this part—
Firm as it relates to architect-engineer services, means any individual, partnership, corporation, association, or other legal entity permitted by law to practice the professions of architecture or engineering.
36.002 Policy.
(a) Agencies must require the use of a project labor agreement for Federal construction projects with a total estimated construction cost at or above $35 million, unless an exception applies (see Part 22).
(b) Contracting officers conducting market research for Federal construction contracts valued at or above $35 million, must ensure that the market research procedures (see Part 10) involve a current and proactive examination of the market conditions in the project area to determine national, regional, and local entity interest in participating on a project that requires a project labor agreement, and to understand the availability of unions, and unionized and non-unionized contractors. Contracting officers may coordinate with agency labor advisors, as appropriate.
(c) The contracting officer must use one of the following acquisition procedures when contracting for the design and construction of a public building, facility, or work:
(1) Design-bid-build established under 40 U.S.C. chapter 11, Selection of Architects and Engineers.
(2) Two-phase design-build selection procedures authorized by 10 U.S.C. 3241 or 41 U.S.C. 3309.
(3) Another acquisition procedure authorized by law.
(d) Agencies must implement high-performance sustainable building design, construction, renovation, repair, commissioning, operation and maintenance, management, and deconstruction practices to ensure that—
(1) All new construction and modernization projects greater than 25,000 gross square feet are designed, constructed, and maintained to meet or exceed Government sustainable design and operations principles in accordance with the Council on Environmental Quality's Guiding Principles for Sustainable Federal Buildings and Associated Instructions (Guiding Principles) (available at https://www.sustainability.gov/pdfs/guiding_principles_for_sustainable_federal_buildings.pdf);
(2) All renovation projects of existing Federal buildings/facilities must use, to the greatest extent possible, Government sustainable design and operations principles for existing buildings in accordance with the Guiding Principles; and
(3) Rehabilitation of Federally-owned historic buildings utilizes best practices and technologies in retrofitting to promote long-term viability of the buildings.
Subpart 36.1 - Pre-solicitation
36.101 Construction.
36.101-1 Acquisition Strategy.
(a) The contracting officer will only use sealed bid procedures (see part 14) for a construction contract if the conditions in part 6 for use of sealed bidding are met. However, the contracting officer should not use sealed bidding if the contract will be performed outside the United States and its outlying areas.
(b) The following must be considered when determining the contract type and pricing structure and must be addressed in the acquisition plan.
(1) Generally, firm-fixed-price contracts must be used to acquire construction. They may be priced—
(i) on a lump-sum basis (when a lump sum is paid for the total work or defined parts of the work),
(ii) on a unit-price basis (when a unit price is paid for a specified quantity of work units), or
(iii) using a combination of the two methods.
(2) Lump-sum pricing must be used in preference to unit pricing except when—
(i) Large quantities of work such as grading, paving, building outside utilities, or site preparation are involved;
(ii) Quantities of work, such as excavation, cannot be estimated with sufficient confidence to permit a lump-sum offer without a substantial contingency;
(iii) Estimated quantities of work required may change significantly during construction; or
(iv) Offerors would have to expend unusual effort to develop adequate estimates.
(3) Fixed-price contracts with economic price adjustment may be used if such a provision is customary in contracts for the type of work being acquired, or when omission of an adjustment provision would preclude a significant number of firms from submitting offers or would result in offerors including unwarranted contingencies in proposed prices.
(4) In view of potential labor and administrative problems, cost-plus-fixed-fee, price-incentive, or other types of contracts with cost variation or cost adjustment features must not be permitted concurrently, at the same work site, with firm-fixed-price, lump sum, or unit price contracts except with the prior approval of the head of the contracting activity.
36.101-2 Use of two-phase design-build selection procedures.
(a) As authorized by 10 U.S.C. 3241 and 41 U.S.C. 3309, the two-phase design-build selection procedures may be used when the contracting officer determines in writing that this method is appropriate, based on the following:
(1) Three or more offers are anticipated.
(2)Design work must be performed by offerors before developing price or cost proposals, and a substantial expense will be incurred in preparing offers.
(3) That the contracting officer has considered:
(i) The extent to which the project requirements have been adequately defined.
(ii) The time constraints for delivery of the project.
(iii) The capability and experience of potential contractors.
(iv) The suitability of the project for use of the two-phase selection method.
(v) The capability of the agency to manage the two-phase selection process.
(vi) Other criteria established by the agency.
(b) Phase-one of the solicitation(s) must include—
(1) The scope of work;
(2) The phase-one evaluation factors, which must include—
(i) Technical approach (excluding detailed design or technical information);
(ii) Technical qualifications, such as—
(A) Specialized experience and technical competence;
(B) Capability to perform;
(C) Past performance of the offeror's team (including the architect-engineer and construction members); and
(iii) Other appropriate factors (excluding cost or price related factors);
(3) Phase-two evaluation factors (see paragraph (d) of this section); and
(4) A statement of the maximum number of offerors that will be selected to submit phase-two proposals. Unless the contracting officer determines in writing that a number greater than five is in the Government's interest, no more than five offerors can be selected for phase-two proposals.
(c) After evaluating phase-one proposals in accordance with the solicitation, the contracting officer must select the most highly qualified offerors and request those offerors submit phase-two proposals.
(d) Phase-two of the solicitation(s) must—
(1) Be prepared and evaluated in accordance with part 15;
(2) Include phase-two evaluation factors, such as design concepts and proposed technical solutions; and
(3) Require submission of separate technical and price proposals.
36.101-3 Scope of work.
(a) A scope of work must be included in the solicitation, and must:
(1) Define the project; and
(2)Provide prospective offerors with sufficient information regarding the Government's requirements.
(b) The scope of work may include criteria and preliminary design, budget parameters, and schedule or delivery requirements.
(c) If the agency contracts for development of the scope of work, it must use the procedures in sections 36.102 and 36.202.
36.101-4 Advance notices and solicitations.
(a) A description of agency policies or procedures, in addition to that outlined in part 43, that apply to definitization of equitable adjustments for change orders under construction contracts.
(b) Data on the agency's past performance, for the prior 3 fiscal years, regarding the time required to definitize equitable adjustments for change orders under construction contracts (see part 43). Agencies must provide the data shown in the following table, or provide the address of an agency-specific, publicly accessible website containing this information.
Time to definitize after receipt of an adequate change order definitization proposal under construction contracts | Number of change order proposals definitized under construction contracts |
---|---|
30 days or less | |
31 to 60 days | |
61 to 90 days | |
91 to 180 days | |
181 to 365 days | |
366 or more days | |
After completion of contract performance via a contract modification addressing all undefinitized equitable adjustments received during contract performance |
36.101-5 Liquidated damages.
During acquisition planning the contracting officer must evaluate the need for liquidated damages in a construction contract in accordance with part 11 and agency policies.
36.101-6 Government cost estimate.
(a) An independent Government estimate (IGE) of the cost of construction must be prepared for any action expected to exceed the simplified acquisition threshold. The IGE must be prepared based on a detailed analysis of the requirements.
(b) The IGE must be given to the contracting officer before receipt of any proposals. When two-step sealed bidding is used, the independent Government estimate must be prepared when the contract requirements are definitized.
36.101-7 Clauses.
(a) The contracting officer must insert the clauses in Table 1 in solicitations and contracts when a fixed-price construction contract or a fixed-price dismantling, demolition, or removal of improvements contract is contemplated, and the contract amount is expected to exceed the simplified acquisition threshold. The Table 1 clauses may be used for contracts valued at or below the simplified acquisition threshold.
Clause | Title |
---|---|
52.236-2 | Differing Site Conditions |
52.236-3 | Site Investigation and Conditions Affecting the Work |
52.236-6 | Superintendence by the Contractor |
52.236-8 | Other Contracts |
52.236-9 | Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements |
52.236-10 | Operations and Storage Areas |
52.236-12 | Cleaning Up |
(b) The contracting officer must insert the clause at 52.236-5, Material and Workmanship, in solicitations and contracts for construction.
(c) The contracting officer must insert the clause at 52.236-7, Permits and Responsibilities, in solicitations and contracts when a fixed-price or cost-reimbursement construction contract or a fixed-price dismantling, demolition, or removal of improvements contract is contemplated.
(d)
(1) The contracting officer must insert the clause at 52.236-11, Use and Possession Prior to Completion, in solicitations and contracts when a fixed-price construction contract is contemplated, and the contract award amount is expected to exceed the simplified acquisition threshold.
(2) This clause may be inserted in solicitations and contracts when the contract amount is expected to be at or below the simplified acquisition threshold.
(e) The contracting officer must insert the clause at 52.236-13, Accident Prevention, in solicitations and contracts when a fixed-price construction contract or a fixed-price dismantling, demolition, or removal of improvements contract is contemplated, and the contract amount is expected to exceed the simplified acquisition threshold.
(1) This clause may be inserted in solicitations and contracts when the contract amount is expected to be at or below the simplified acquisition threshold.
(2) The clause must be used with its Alternate I when a contract for services will involve:
(i) Work of a long duration or hazardous nature; or
(ii) Performance on a Government facility that on the advice of technical representatives involves hazardous materials or operations that might endanger the safety of the public and/or Government personnel or property.
(f)
(1) The contracting officer must insert the clause at 52.236-14, Availability and Use of Utility Services, in solicitations and contracts when a fixed-price construction contract or a fixed-price dismantling, demolition, or removal of improvements contract is contemplated, the contract is to be performed on Government sites, and the contracting officer decides that—
(i) The existing utility system(s) is adequate for the needs of both the Government and the contractor; and
(ii) Furnishing it is in the Government's interest.
(2) When this clause is used, the contracting officer must list the available utilities in the contract.
(g)
(1) The contracting officer may insert the clause at 52.236-15, Schedules for Construction Contracts, in solicitations and contracts when a fixed-price construction contract is contemplated, the contract amount is expected to exceed the simplified acquisition threshold, and—
(i) The period of actual work performance exceeds 60 days; or
(ii) When work performance is expected to last less than 60 days and an unusual situation exists that warrants imposition of the requirements.
(2) Contracting officers should not insert the clause in paragraph (g)(1) of this section, in the same contract with clauses covering other management approaches for ensuring that a contractor makes adequate progress.
(h) The contracting officer may insert the clause at 52.236-16, Quantity Surveys, in solicitations and contracts when a fixed-price construction contract providing for unit pricing of items and for payment based on quantity surveys is contemplated. The clause must be used with its Alternate I if it is determined at a level above that of the contracting officer that—
(1) It is impracticable for Government personnel to perform the original and final surveys; and
(2) The Government wishes the contractor to perform these surveys.
(i) The contracting officer must insert the clause at 52.236-17, Layout of Work, in solicitations and contracts when a fixed-price construction contract is contemplated, and use of this clause is appropriate due to a need for accurate work layout and for siting verification during work performance.
(j) The contracting officer must insert the clause at 52.236-18, Work Oversight in Cost-Reimbursement Construction Contracts, in solicitations and contracts when a cost-reimbursement construction contract is contemplated.
(k)
(1) The contracting officer must insert the clause at 52.236-21, Specifications and Drawings for Construction, in solicitations and contracts when a fixed-price construction contract or a fixed-price dismantling, demolition, or removal of improvements contract is contemplated, and the contract amount is expected to exceed the simplified acquisition threshold.
(2) The contracting officer may insert the clause in paragraph (k)(1) of this section in solicitations and contracts when a fixed-price construction or a fixed-price contract for dismantling, demolition, or removal of improvements is contemplated and the contract amount is expected to be at or below the simplified acquisition threshold.
(3) When the Government needs record drawings, the contracting officer must—
(i) Use the clause with its Alternate I, if reproducible shop drawings are needed, or
(ii) Use the clause with its Alternate II, if reproducible shop drawings are not needed.
36.102 Architect-Engineer Services.
36.102-1 Public announcement.
The Government must publicly announce all requirements for architect-engineer services (see 40 U.S.C. 1101 et seq.).
36.102-2 Contracting procedures and competition.
(a) Contracting officers must acquire architect-engineer services by negotiation and select sources in accordance with this section.
(b) The procedures of this section are competitive procedures (see part 6).
(c) Agencies must encourage firms to submit annually an updated statement of qualifications and performance data on a Standard Form (SF) 330, Part II—General Qualifications.
(d)
(1) Surveying is considered to be an architectural and engineering service and must be procured pursuant to sections 36.102 and 36.202 from registered surveyors or architects and engineers. Mapping associated with the research, planning, development, design, construction, or alteration of real property is considered to be an architectural and engineering service and must be procured pursuant to sections 36.102 and 36.202.
(2) Mapping services that are not connected to traditionally understood or accepted architectural and engineering activities, are not incidental to such architectural and engineering activities or have not in themselves traditionally been considered architectural and engineering services must be procured pursuant to provisions in parts 13, 14, and 15.
36.202-3 Government cost estimate.
(a) An independent Government estimate (IGE) of the cost of architect-engineer services must be prepared based on a detailed analysis of the requirements.
(b) The IGE must be given to the contracting officer before beginning negotiations for any action expected to exceed the simplified acquisition threshold.
36.102-4 Clauses.
(a) The contracting officer must insert the clause at 52.236-22, Design Within Funding Limitations, in fixed-price architect-engineer contracts except when—
(1) The head of the contracting activity determines in writing that cost limitations are secondary to performance considerations and additional project funding can be expected;
(2) The design is for a standard structure and is not intended for a specific location; or
(3) There is little or no design effort involved.
(b) The contracting officer must insert the clause at 52.236-23, Responsibility of the Architect-Engineer Contractor, in fixed-price architect-engineer contracts.
(c) The contracting officer must insert the clause at 52.236-24, Work Oversight in Architect-Engineer Contracts, in all architect-engineer contracts.
(d) The contracting officer must insert the clause at 52.236-25, Requirements for Registration of Designers, in architect-engineer contracts, except that it may be omitted when the design will be performed—
(1) Outside the United States and its outlying areas; or
(2) In a State or outlying area of the United States that does not have registration requirements for the particular field involved.
Subpart 36.2 - Special Aspects of Contracting for Construction
36.201 Construction.
36.201-1 Limitations.
The contracting officer must not award a contract for construction—
(a) At a cost to the Government—
(1) In excess of statutory cost limitations, unless applicable limitations can be and are waived in writing for the particular contract; or
(2) Which, with allowances for Government-imposed contingencies and overhead, exceeds the statutory authorization.
(b) To the firm that designed the project or to the firm’s subsidiaries or affiliates, unless approved by the agency head.
36.201-2 Standard and optional forms.
(a) Standard Form 1442, Solicitation, Offer, and Award (Construction, Alteration, or Repair), must be used to solicit and submit offers, and award construction or dismantling, demolition, or removal of improvements contracts expected to exceed the simplified acquisition threshold, and may be used for contracts at or below the simplified acquisition threshold. In all sealed bid solicitations, or when the Government otherwise requires a noncancellable offer acceptance period, the contracting officer must insert in the blank provided in Block 13D the number of calendar days that the offer must be available for acceptance after the date offers are due.
(b) Optional Form 347, Order for Supplies or Services, may be used for construction or dismantling, demolition, or removal of improvements contracts that are at or below the simplified acquisition threshold; provided, that the contracting officer includes the clauses required (see section 36.101-7) in the simplified acquisitions (see part 13).
(c) Contracting officers may use Optional Form 1419, Abstract of Offers—Construction, and Optional Form 1419A, Abstract of Offers—Construction, Continuation Sheet, or the automated equivalents to record offers submitted in response to a sealed bid solicitation (see part 14) and may also use them to record offers submitted in response to negotiated solicitations.
36.202 Architect and engineering services.
36.202-1 Evaluation.
(a)
(1) Agencies must provide for one or more permanent or ad hoc architect-engineer evaluation boards—
(i) Which may include preselection boards when authorized by agency regulations;
(ii) Composed of members who—
(A) Collectively, have experience in architecture, engineering, construction, and Government and related acquisition matters;
(B) Are appointed from among highly qualified professional employees of the agency or other agencies; and
(C) If authorized by agency procedure, are private practitioners of architecture, engineering, or related professions.
(2) One Government member of each board must be designated as the chairperson.
(b) Under the general direction of the head of the contracting activity, an evaluation board must perform the following functions:
(1) For each proposed project, evaluate the firms’ Standard Form (SF) 330, Part II—General Qualifications, together, if necessary, with data submitted on the SF 330, Part I—Contract-Specific Qualifications, either already on file with the agency or submitted regarding the proposed project.
(2) Conduct discussions with at least 3 firms to consider anticipated concepts and compare alternative methods for furnishing services.
(3) Prepare a selection report for the agency head or other designated selection authority recommending, in order of preference, at least three firms that are considered to be the most highly qualified to perform the required services. The report must include a description of the discussions and evaluation conducted by the board to allow the selection authority to review the considerations upon which the recommendations are based.
36.202-2 Selection authority.
(a) The final selection decision must be made by the agency head or a designated selection authority.
(b) The final selection must be made by reviewing and considering the selection report and advice of technical and staff representatives.
(1) The final selection must be a listing, in order of preference, of the firms considered most highly qualified to perform the work.
(2) The selection authority must not add firms to the selection report.
(3) If the firm listed as the most preferred is not the firm recommended as the most highly qualified, the selection authority must provide a written explanation of the reason for the preference for inclusion in the contract file.
(4) If the firms recommended in the report are not deemed to be qualified or the report is considered inadequate for any reason, the selection authority must record the reasons and return the report for appropriate revision.
(c) All firms on the final selection list are considered selected firms with which the contracting officer may negotiate.
36.202-3 Government cost estimate.
(a) An independent Government estimate (IGE) of the cost of architect-engineer services must be prepared based on a detailed analysis of the requirements.
(b) The IGE must be given to the contracting officer before beginning negotiations for any action expected to exceed the simplified acquisition threshold.
36.202-4 Short selection process for contracts not to exceed the simplified acquisition threshold.
When authorized by the agency, either or both of the short processes described in this subsection may be used to select firms for contracts not expected to exceed the simplified acquisition threshold. Otherwise, the procedures prescribed in 36.202-1, 36.202-2, and 36.202-3 must be followed.
(a) Selection by the board. The board must review and evaluate architect-engineer firms in accordance with 36.202-1, except that the selection report serves as the final selection list and must be provided directly to the contracting officer. The report serves as the authorization for the contracting officer to commence negotiations in accordance with 36.202-3.
(b) Selection by the chairperson of the board. When the board decides that formal action by the board is not necessary in connection with a particular selection, the following procedures must be followed:
(1) The chairperson of the board must perform the functions required in 36.202-1(b).
(2) The agency head or designated selection authority must review the report and approve it or return it to the chairperson for appropriate revision.
(3) Upon receipt of an approved report, the chairperson of the board must provide a copy of the report to the contracting officer which will serve as the authorization for the contracting officer to commence negotiations in accordance with 36.202-3.
36.202-5 Standard and optional forms.
(a)Contracting officers must use Standard Form (SF) 252, Architect-Engineer Contract, to award fixed-price contracts for architect-engineer services when the services will be performed in the United States or its outlying areas.
(b)The firm’s qualifications as listed in the SF 330, Part II—General Qualifications as well as the SF 330, Part I—Contract-Specific Qualifications, must be used to evaluate firms before awarding a contract for architect-engineer services:
(1) Use the SF 330, Part I—Contract-Specific Qualifications, to obtain information from an architect-engineer firm about its qualifications for a specific contract when the contract amount is expected to exceed the simplified acquisition threshold. Part I may be used when the contract amount is expected to be at or below the simplified acquisition threshold, if the contracting officer determines that its use is appropriate.
(2) Use the SF 330, Part II—General Qualifications, to obtain information from an architect-engineer firm about its general professional qualifications.
Subpart 36.3 - Postaward
36.301 Responsibilities of contracting officers.
See part 42 for performing general contract administration functions. For construction and architect-engineer services there are additional functions including:
(a) Performance and Deliverables.
(1) Contracting officers can, in writing, request the removal of any contractor employee deemed incompetent, careless, or otherwise objectionable (see 52.236-5).
(2) Contracting officers must provide the contractor with a list of work remaining to be performed or corrected for any portions of the work the Government intends to possess or use, prior to taking possession or using said work (see 52.236-11).
(3) Regarding schedules for construction contracts:
(i) The contracting officer may withhold approval of progress payments if the contractor fails to submit the required schedule.
(ii)
(A) The contracting officer must determine whether the work is progressing with sufficient diligence to meet the contract's specified completion time; and
(B) May terminate the contractor's right to proceed with the work, or any separable part of it, per the default terms of the contract if the contractor fails to recover lost time (see 52.236-15).
(b) Modifications.
(1) Upon receiving written notice of differing site conditions, the contracting officer must—
(i) Promptly investigate the site; and
(ii) Negotiate an equitable adjustment if the conditions materially differ, leading to an increase or decrease in the contractor's costs or performance time. Requests for an equitable adjustment will be allowed only if prior written notice is received or if submitted before final payment (see 52.236-2).
(2) If repairs are not made promptly to damaged existing vegetation, structures, equipment, utilities, or improvements; contracting officers may have the necessary work performed and charge the cost to the contractor (see 52.236-9).
(3) If stakes and marks are destroyed by the contractor, the contracting officer may replace them and deduct the cost from due or future payments (see 52.236-17).
(4) Regarding specifications and drawings for construction—
(i) The contracting officer must—
(A) Make a written determination in the case of a discrepancy in the figures, in the drawings, or in the specifications; and
(B) Approve or disapprove shop drawings, with reasons for disapproval if applicable.
(ii) If the contracting officer approves a shop drawing variation from the contract requirements that is minor or does not impact price or performance time, a contract modification will not be issued. For all other approved variations, the contracting officer must issue a contract modification (see 52.236-21).
(5) If a construction contract needs a modification due to architect-engineer design errors, the contracting officer must—
(i) Assess the architect-engineer's liability, with the advice of technical personnel and legal counsel;
(ii) Seek cost recovery if the amount exceeds administrative costs or if it benefits the Government; and
(iii) Include in the contract file a written statement detailing the recovery decision (see 52.236-23).
(c) Compliance and Reporting.
(1) Contracting officers must ensure compliance with the labor standards requirement of the contract (e.g., payroll reviews, on-site inspections, and employee interviews to determine compliance).
(2) Contracting officers should advise contractors to promptly execute and return any required payment and performance bonds to ensure a notice to proceed is issued to commence work in a timely manner (see part 28).
(3) Contracting officers must, if appropriate, give written consent for the contractor to abandon, without removal, temporary buildings and utilities. (see 52.236-10).
(4) If the contracting officer becomes aware of noncompliance with requirements or conditions that endanger public or Government personnel health or safety, the contracting officer—
(i) Must notify the contractor orally, then in writing, requesting immediate corrective action; and
(ii) May issue a stop-work order if the contractor fails to promptly take satisfactory corrective action. (see 52.236-13).
Feedback
We welcome informal input on the revised FAR :
Non-regulatory Resources
The following are non-regulatory resources associated with FAR :
FAR Companion Guide Coming Soon.
Caveat
The FAR Council created deviations will include clauses and provisions currently required by statute and Executive Order. OMB and the FAR Council will work with Congress to recommend statutory changes and with the White House to recommend rescission of requirements stemming from prior Executive Orders that are inconsistent with the goals of Executive Order 14275 to stop the inefficient use of American taxpayer dollars in federal procurement. Any changes to Executive Orders or statute will be reflected when the Revolutionary FAR Overhaul turns to rule-making.