PART 5333
Protests, Disputes, and Appeals
[2013 Edition]
(b)(3)(ii) See MP5301.601(a)(i).
5333.103 Protests to the Agency
(d)(4) When an agency protest is denied, an offeror may request an independent review by the MAJCOM/DRU/AFISRA SCO (or for AFLCMC and SMC, the SCCO).
(h) The contracting officer must prepare the protest file following an agency protest (including a protest of a non-appropriated funds procurement) regardless of the level at which the protest is filed. The contracting officer must request guidance from SAF/AQC for any protest likely to generate significant Congressional interest. The decision to deny a protest must be made at a level no lower than that at which the protest was filed. Protests may be sustained at any level in the review process, with the concurrence of the cognizant legal office.
5333.104 Protests to GAO
(a) The Commercial Law and Litigation Directorate of the Air Force Legal Operations Agency (AFLOA/JAQ) serves as agency counsel before the GAO and defends Air Force interests (see MP5333.104).
(b) Protests before award.
(1) Forward the determination and finding through the MAJCOM/DRU/AFISRA SCO (or for AFLCMC, the SCCO) to AFLOA/JAQ and, for approval, to SAF/AQC within seven days of the protest notification to SAF/AQC (see MP5301.601(a)(i)).
(c) Protests after award.
(2) Forward the determination and finding through the MAJCOM/DRU/AFISRA SCO (or for AFLCMC, the SCCO) to AFLOA/JAQ and, for approval, to SAF/AQC within seven days of the protest notification to SAF/AQC (see MP5301.601(a)(i)).
Forward the report through the MAJCOM/DRU/AFISRA SCO (or for AFLCMC, the SCCO) to AFLOA/JAQ and to SAF/AQC for signature and submission to GAO within fifty-five days of date of receipt of the GAO recommendations (see MP5301.601(a)(i)).
5333.105 Protests to the United States Court of Federal Claims (COFC)
The Commercial Law and Litigation Directorate of the Air Force Legal Operations Agency (AFLOA/JAQ) serves as the Air Force agency counsel to the Department of Justice (DoJ) for protests at the COFC and assists the assigned DoJ attorney in defending Air Force interests. The contracting officer must inform AFLOA/JAQ of any notice of protest at the COFC and provide support as requested by AFLOA/JAQ. Also notify the MAJCOM/DRU/AFISRA SCO (or for AFLCMC and SMC, the SCCO) and the supporting field legal office.
5333.170 Briefing Requirement for Protested Acquisitions Valued at $1B or More
Forward the briefing slide deck through the MAJCOM/DRU/AFISRA SCO (or for AFLCMC, the SCCO) to AFLOA/JAQ and to SAF/AQC for review within seven (7) days of the filing of the protest.
SUBPART 5333.2 — DISPUTES AND APPEALS
5333.214 Alternate Dispute Resolution (ADR)
(a) For ACAT I and II programs, the contracting officer must establish an agreement between the Government and the contractor, such as a memorandum of understanding, that outlines the intent of the parties with respect to the use of ADR. Contracting officers must consider establishing ADR agreements for other programs and acquisitions.
(c) The acquisition team must use ADR to the maximum extent practicable (see AFPD 51-12, Alternate Disputes Resolution). ADR must also be used to resolve protests to the maximum extent practicable. The acquisition team must attempt to use ADR prior to the commencement of litigation once unassisted negotiations have reached an impasse. Further, ADR must be offered in litigation, unless one of the exceptions in 5 U.S.C. 572(b) applies or the policy set forth by Deputy General Counsel (Dispute Resolution (SAF/GCD)) indicates that ADR is not appropriate.
(3) See MP5301.601(a)(i).
5333.290 Claims and Terminations for Default
(a) If a contractor submits an uncertified claim exceeding $100,000, the contracting officer must notify the contractor, in writing, of its failure to certify as required by the Contract Disputes statute) (41 U.S.C. §§ 7101-7109). The notice must state that a final decision will not be issued until the claim is certified.
(b) Prior to making a final decision on a claim or termination for default (including a termination for cause under FAR Part 12), the contracting officer must refer the proposed final decision to the cognizant legal office for legal advice, ADR suitability, and appropriate dispute resolution strategies. The contracting officer, with the assistance of the cognizant legal office, must seek review by AFLOA/JAQ of all proposed final decisions. At the same time, the contracting officer must provide SAF/GCD with any proposed final decision on a claim involving PEO programs, any proposed final decision on a claim greater than $500,000, or any proposed termination for default with estimated excess reprocurement costs greater than $500,000. The contracting officer or the referring person must promptly notify SAF/GCR and their MAJCOM/DRU/AFISRA SCO (or for AFLCMC, the SCCO) with all known information relating to any recommended termination for default.
(c) The contracting officer must use ADR to the maximum extent practicable to resolve an Air Force affirmative contract claim (such as defective pricing, liquidated damages, etc.) when unassisted negotiations reach an impasse as determined by the MAJCOM/DRU/AFISRA SCO (or for AFLCMC and SMC, the SCCO). The contracting officer must provide to AFLOA/JAQ, with a copy to SAF/GCD, any audit or other findings indicating Air Force entitlement to recovery greater than $500,000 where unassisted negotiations have reached an impasse, in order to develop a dispute resolution strategy. Government claims must be formally asserted [issuance of a Contracting Officer’s Final Decision (FAR 33.206)] within 6 years after the accrual of the claim.
5333.291 Appeals to the Armed Services Board of Contract Appeals (ASBCA)
(a) AFLOA/JAQ represents the Air Force in appeals to the ASBCA.
(b) If the contractor files an appeal with the ASBCA, the contracting officer must notify the MAJCOM/DRU/AFISRA SCO (or for AFLCMC, the SCCO) and forward to AFLOA/JAQ and the cognizant legal office a copy of any notice of appeal to the ASBCA, along with the envelope in which the notice was received. If the contractor files an appeal with the contracting officer instead of the ASBCA, the contracting officer must immediately notify AFLOA/JAQ of the date the appeal was received and forward to AFLOA/JAQ and the cognizant legal office a copy of the appeal and a copy of the envelope in which the appeal was received. The contracting officer must forward the original appeal and envelope to AFLOA/JAQ, which will then forward the appeal and envelope to the ASBCA, as necessary.
(c) The contracting officer must prepare a “Rule 4 file” for any appeal to the ASBCA in accordance with Rule 4 of the ASBCA rules (see DFARS Appendix A, Part 2). The contracting officer must consult with AFLOA/JAQ before including in the Rule 4 file any legal opinions or intra-governmental or inter-governmental documents as described in DoD Regulation 5400.7, DoD Freedom of Information Act Program; the Air Force Supplement to DoD 5400.7-R; and FAR 24.2.
(d) While an appeal is pending, the contracting officer along with the program manager/user/functional Commander and SJA will support the assigned trial attorney as required including; identifying and locating government witnesses, gathering contractual documents and other physical evidence for conferences and hearings necessary to defend or otherwise dispose of an appeal.
(e) Once the Rule 4 file is complete, AFLOA/JAQ will file it with the ASBCA on behalf of the contracting officer.
5333.292 Appeals to the United States Court of Federal Claims (COFC)
(a) The Department of Justice represents the Air Force in appeals brought before the COFC. The Commercial Law and Litigation Directorate (AFLOA/JAQ) serves as the Air Force counsel with the Department of Justice in such appeals.
(b) The contracting officer must notify the cognizant legal office and the MAJCOM/DRU/AFISRA SCO (or for AFLCMC, the SCCO) of any notice of appeal to the COFC. The cognizant legal office must forward a copy of the notice to SAF/GCD and AFLOA/JAQ.
(c) The contracting officer must assist the cognizant legal office in preparing the litigation report. The contracting officer must obtain approval from the AFLOA/JAQ trial attorney prior to releasing the litigation report outside government.